- Definitions
- “Contract” means the terms and conditions contained herein, together with any quotation, order, invoice or other document or amendments expressed to be supplemental to this Contract.
- “Contractor” means Swarly Pty Ltd, its successors and assigns or any person acting on behalf of and with the authority of Swarly Pty Ltd.
- “Client” means the person/s, entities or any person acting on behalf of and with the authority of the Client requesting the Contractor to provide the Works as specified in any proposal, quotation, order, invoice or other documentation, and:
- if there is more than one Client, is a reference to each Client jointly and severally; and
- if the Client is a partnership, it shall bind each partner jointly and severally; and
- if the Client is a part of a Trust, shall be bound in their capacity as a trustee; and
- includes the Client’s executors, administrators, successors and permitted assigns.
- “Works” means all Works (including consultation, manufacturing and/or installation services) or Materials supplied by the Contractor to the Client at the Client’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).
- “Worksite” means the address nominated by the Client to which the Materials are to be supplied by the Contractor.
- “Intended Use” means a building product and the use thereof, for which the building product is intended to be, or is reasonably likely to be, associated with a building.
- “Non-Conforming Building Product” means building products that are regarded as Non-Conforming for an Intended Use if, when associated with a building:
- the product is not, or will not be, safe; or
- does not, or will not, comply with the relevant regulatory provisions; or
- the product does not perform, or is not capable of performing, for the use to the standard it is represented to conform by or for a person in the chain of responsibility for the product.
- “Confidential Information” means information of a confidential nature whether oral, written or in electronic form including, but not limited to, this Contract, either party’s intellectual property, operational information, know-how, trade secrets, financial and commercial affairs, contracts, client information (including but not limited to, “Personal Information” such as: name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) and pricing details.
- “Cookies” means small files which are stored on a user’s computer. They are designed to hold a modest amount of data (including Personal Information) specific to a particular client and website, and can be accessed either by the web server or the client’s computer. If the Client does not wish to allow Cookies to operate in the background when using the Contractor’s website, then the Client shall have the right to enable / disable the Cookies first by selecting the option to enable / disable provided on the website, prior to making enquiries via the website.
- “Price” means the Price payable (plus any GST where applicable) for the Works as agreed between the Contractor and the Client in accordance with clause 6
- “GST” means Goods and Services Tax as defined within the “A New Tax System (Goods and Services Tax) Act 1999” (Cth).
- Acceptance
- The Client is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Client places an order for or accepts delivery of any Works.
- In the event of any inconsistency between the terms and conditions of this Contract and any other prior document or schedule that the parties have entered into, the terms of this Contract shall prevail.
- Any amendment to the terms and conditions contained in this Contract may only be amended in writing by the consent of both parties.
- The Client acknowledges that the supply of Works on credit shall not take effect until the Client has completed a credit application with the Contractor and it has been approved with a credit limit established for the account.
- In the event that the supply of Works requested exceeds the Client’s credit limit and/or the account exceeds the payment terms, the Contractor reserves the right to refuse delivery.
- Electronic signatures shall be deemed to be accepted by either party providing that the parties have complied with Section 14 of the Electronic Transactions (Queensland) Act 2001 or any other applicable provisions of that Act or any Regulations referred to in that Act.
- Authorised Representatives
- The Client acknowledges that the Contractor shall (for the duration of the Works) liaise directly with one (1) authorised representative, and that once introduced as such to the Contractor, that person shall have the full authority of the Client to order any Works and/or to request any variation thereto on the Client’s behalf. The Client accepts that they will be solely liable to the Contractor for all additional costs incurred by the Contractor (including the Contractor’s profit margin) in providing any Works or variation/s requested thereto by the Client duly authorised representative.
- Errors and Omissions
- The Client acknowledges and accepts that the Contractor shall, without prejudice, accept no liability in respect of any alleged or actual error(s) and/or omission(s):
- resulting from an inadvertent mistake made by the Contractor in the formation and/or administration of this Contract; and/or
- contained in/omitted from any literature (hard copy and/or electronic) supplied by the Contractor in respect of the Works.
- In the event such an error and/or omission occurs in accordance with clause 1, and is not attributable to the negligence and/or wilful misconduct of the Contractor; the Client shall not be entitled to treat this Contract as repudiated nor render it invalid.
- The Client acknowledges and accepts that the Contractor shall, without prejudice, accept no liability in respect of any alleged or actual error(s) and/or omission(s):
- Change in Control
- The Client shall give the Contractor not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client and/or any other change in the Client’s details (including but not limited to, changes in the Client’s name, address, contact phone or fax number/s, change of trustees, or business practice). The Client shall be liable for any loss incurred by the Contractor as a result of the Client’s failure to comply with this clause.
- Price and Payment
- At the Contractor’s sole discretion the Price shall be either:
- as indicated on invoices provided by the Contractor to the Client in respect of Works performed or Materials supplied; or
- the Contractor’s quoted Price (subject to clause 2) which shall be binding upon the Contractor provided that the Client shall accept the Contractor’s quotation in writing within thirty (30) days.
- The Contractor reserves the right to change the Price:
- if a variation to the Materials which are to be supplied is requested; or
- if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or
- where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, poor weather conditions, availability of machinery, safety considerations, prerequisite work by a third party not being completed, hard rock or other barriers below the surface, latent soil conditions, iron reinforcing rods in concrete, remedial work required due to existing workmanship being of a poor quality or non-compliant to the building code or underground services as per clause 11 ) which are only discovered on commencement of the Works; or
- as a result of an increase in the Contractor’s costs due to changes in statutory, government, or local body charges, taxes, levies, etc. with respect to the Works, increases to the Contractor in the cost of labour or Materials or due to relevant industry awards (e.g. Worksite allowance and severance pay), which are outside the control of the Contractor.
- in the event of increases to the Contractor in the cost of labour or Materials which are beyond the Contractor’s control.
- Variations will be charged for on the basis of the Contractor’s quotation, and will be detailed in writing, and shown as variations on the Contractor’s invoice. The Client shall be required to respond to any variation submitted by the Contractor within ten (10) working days. Failure to do so will entitle the Contractor to add the cost of the variation to the Price. Payment for all variations must be made in full at the time of their completion.
- At the Contractor’s sole discretion a non-refundable deposit may be required.
- Time for payment for the Works being of the essence, the Price will be payable by the Client on the date/s determined by the Contractor, which may be:
- on completion of the Works; or
- by way of progress payments in accordance with the Contractor’s specified progress payment schedule. Such progress payment claims may include the reasonable value of authorised variations and the value of any Materials delivered to the Worksite but not yet installed; or
- thirty (30) days following the end of the month in which a statement is emailed or posted to the Client’s address or address for notices;
- the date specified on any invoice or other form as being the date for payment; or
- failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Client by the Contractor.
- Payment may be made by cash, bank cheque, electronic/on-line banking, credit card (a surcharge may apply per transaction), or by any other method as agreed to between the Client and the Contractor.
- The Contractor may in its discretion allocate any payment received from the Client towards any invoice that the Contractor determines and may do so at the time of receipt or at any time afterwards. On any default by the Client the Contractor may re-allocate any payments previously received and allocated. In the absence of any payment allocation by the Contractor, payment will be deemed to be allocated in such manner as preserves the maximum value of the Contractor’s Purchase Money Security Interest (as defined in the PPSA) in the Materials.
- The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by the Contractor nor to withhold payment of any invoice because part of that invoice is in dispute.
- Unless otherwise stated the Price does not include GST. In addition to the Price, the Client must pay to the Contractor an amount equal to any GST the Contractor must pay for any supply by the Contractor under this or any other contract for the sale of the Materials. The Client must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Client pays the Price. In addition, the Client must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.
- At the Contractor’s sole discretion the Price shall be either:
- Provision of the Works
- Subject to clause 2 it is the Contractor’s responsibility to ensure that the Works start as soon as it is reasonably possible.
- The Works’ commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that the Contractor claims an extension of time (by giving the Client written notice) where completion is delayed by an event beyond the Contractor’s control, including but not limited to any failure by the Client to:
- make a selection; or
- have the Worksite ready for the Works; or
- notify the Contractor that the Worksite is ready.
- At the Contractor’s sole discretion, the cost of delivery is either included in the Price or is in addition to the Price.
- The Contractor may deliver the Works by separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.
- Any time specified by the Contractor for delivery of the Works is an estimate only and the Contractor will not be liable for any loss or damage incurred by the Client as a result of delivery being late. However both parties agree that they shall make every endeavour to enable the Works to be supplied at the time and place as was arranged between both parties. In the event that the Contractor is unable to supply the Works as agreed solely due to any action or inaction of the Client, then the Contractor shall be entitled to charge a reasonable fee for re-supplying the Works at a later time and date, and/or for storage of the Materials.
- Worksite Access and Condition
- The Contractor is not responsible for the removal of rubbish from or clean-up of the building/construction Worksite/s. All rubbish generated by the Contractor will be placed in a designated areas appointed by the Client but the responsibility of removal of same is the Client or the Client’s agent, unless otherwise agreed.
- It is the intention of the Contractor and agreed by the Client that:
- the Client shall ensure that the Contractor has clear and free access to the Worksite at all times to enable them to undertake the Works (including carrying out Worksite inspections, gain signatures for required documents, and for the delivery and installation of the Materials). The Contractor shall not be liable for any loss or damage to the Worksite (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of the Contractor; and
- it is the Client’s responsibility to provide the Contractor, while at the Worksite, with adequate access to available water, electricity, toilet and washing facilities; and
- the Client shall contact adjoining neighbours and gain their permission to remove any walls or fences on boundaries and unless otherwise agreed, it shall be the Client’s responsibility to organise either temporary fencing and/or security guards to secure the Worksite during the performance of the Works by the Contractor and shall be liable for all costs associated in taking all reasonable precautions to protect against destruction or damage by way of vandalism or theft. Failure to comply with this clause 2(c) in the event that the Worksite is destroyed or damaged due to vandalism then the cost of repair or replacement shall be borne by the Client.
- The Client agrees to be present at the Worksite when and as reasonably requested by the Contractor and its employees, contractors and/or agents.
- Worksite Inductions
- in the event the Client requires an employee or sub-contractor of the Contractor to undertake a Worksite induction during working hours, the Client will be liable to pay the hourly charges for that period. If any induction needs to be undertaken prior to the commencement date then the Client shall be liable to pay the Contractor’s standard (and/or overtime, if applicable) hourly labour rate; or
- where the Contractor is in control of the Worksite, the Client and/or the Client’s third party contractors must initially carry out the Contractor’s Health & Safety induction course before access to the Worksite will be granted. Inspection of the Worksite during the course of the Works will be by appointment only and unless otherwise agreed, in such an event the Client and/or third party acting on behalf of the Client must at all times be accompanied by the Contractor.
- Dimensions, Plans and Specifications
- The Contractor shall be entitled to rely on the accuracy of any plans, specifications and other information provided by the Client. The Client acknowledges and agrees that in the event that any of this information provided by the Client is inaccurate, The Contractor accepts no responsibility for any loss, damages, or costs however resulting from these inaccurate plans, specifications or other information.
- All customary building industry tolerances shall apply to the dimensions and measurements of the Works unless the Contractor and the Client agree otherwise in writing.
- Where the Client is to supply the Contractor with any design specifications (including, but not limited to CAD drawings) the Client shall be responsible for providing accurate data. The Contractor shall not be liable whatsoever for any errors in the Works that are caused by incorrect or inaccurate data being supplied by the Client.
- In the event the Client gives information relating to measurements and quantities of Materials required in completing the Works, it is the Client’s responsibility to verify the accuracy of the measurements and quantities, before the Client or the Contractor places an order based on these measurements and quantities. The Contractor accepts no responsibility for any loss, damages, or costs however resulting from the Client’s failure to comply with this clause.
- Detailed drawings of any services that will be embedded in the concrete, asphalt or other materials are to be provided to the Contractor prior to commencement of any Works. Whilst all due care will be taken no liability will be accepted by the Contractor for damage to the Works or any other element embedded in the concrete, asphalt or other materials.
- Risk
- If the Contractor retains ownership of the Materials under clause 14 then where the Contractor is supplying Materials only, all risk for the Materials shall immediately pass to the Client on delivery and the Client must insure the Materials on or before delivery. Delivery of the Materials shall be deemed to have taken place immediately at the time that the Materials are delivered by the Contractor or the Contractor’s nominated carrier to the Client’s nominated delivery address (even if the Client is not present at the address).
- Where the Contractor is to both supply and install Materials then the Contractor shall maintain a contract works insurance policy until the Works are completed. Upon completion of the Works all risk for the Works shall immediately pass to the Client.
- Notwithstanding the provisions of clause 1 if the Client specifically requests the Contractor to leave Materials outside the Contractor’s premises for collection or to deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Client and it shall be the Client’s responsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Client’s expense.
- Where the Contractor is required to install the Materials the Client warrants that the structure of the premises or equipment in or upon which these Materials are to be installed or erected is sound and will sustain the installation and work incidental thereto and the Contractor shall not be liable for any claims, demands, losses, damages, costs and expenses howsoever caused or arising in connection with the installation and work incidental thereto.
- The Client acknowledges that, under no circumstances, will the Contractor handle removal of asbestos product. In the event asbestos (or other hazardous material) is discovered on the Worksite:
- the Contractor shall suspend the Works; and
- the Client shall be fully responsible for the resolution of any resulting problems; and
- any additional cost incurred by the Contractor shall be added to the Price under clause 2.
- In the event that during the course of the Works the Contractor discovers any fossils, artefacts or any other remains of geological or archaeological interest are discovered the Contractor reserves the right to halt all Works, remove any of their equipment from the Worksite and immediately notify the Client. Unless the Client accepts and agrees that all additional costs that may be incurred by the Contractor as a result of any such delays (including but not limited to in the event the Contractor is unable to remove their equipment from the Worksite, etc.) shall be borne by the Client and shall be treated as a variation in accordance with clause 2.
- Detailed drawings of any services that will be embedded in the asphalt are to be provided to the Contractor prior to commencement of any Works. Whilst all due care will be taken no liability will be accepted by the Contractor for damage to the Services or any other element embedded in the concrete.
- The Client acknowledges that:
- the curing time for asphalt can be affected by elements such as temperature or the weather as such the Contractor offers no guarantee as to the length of time the curing process will take; and
- where the Contractor is engaged to repair and/or replace a damaged asphalt surface that the Contractor is only responsible for that portion of Works. the Contractor does not at any stage accept any liability in respect of previous Works carried out by any other third party that subsequently fail and found to be the source of the failure, the Client agrees to indemnify the Contractor against any loss or damage to the Materials, or caused by the Materials, or any part thereof howsoever arising;
- the Contractor offers no guarantee against cracking of asphalt.
- The Contractor shall not be held liable for any loss, damages, or costs, howsoever resulting from the Contractor laying asphalt on a base that has been prepared and/or approved by the Client, or a third party.
- Notwithstanding clause 9 the Contractor reserves the right to inspect any base ground works prior to laying of asphalt where the Contractor did not prepare the site and in such an event where the base is not deemed suitable that could result in shrinkage of asphalt, the Contractor shall be entitle to seek an extension of time until such time as the Client gives approval to rectify, all such additional costs shall be borne by the Client.
- Underground Locations / Hidden Services
- Unless otherwise agreed in writing between the Client and the Contractor it shall be the Client’s responsibility to advise the precise location of all underground services on the site and clearly mark the same. The mains/services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, communication cables, fibre optic cables, oil pumping mains, and any other services that may be on site.
- If the Client requests the Contractor to engage a service locator then this shall be in addition to the Price and “Dial Before You Dig” must be consulted and any potential underground services marked on site.
- Whilst the Contractor will take all care to avoid damage to any underground services the Client agrees to indemnify the Contractor in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 1
- Compliance with Laws
- The Client and the Contractor shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Works, including any work health and safety laws (WHS) relating or any other relevant safety standards or legislation pertaining to the Works.
- Both parties acknowledge and agree:
- to comply with the National Construction Code of Australia (NCC) and comply with section74AA (products associated with building works and/or the intended use) and section 74AE (Chain of Responsibility) of the QBCC Act 1999 in respect of all workmanship and building products to be supplied during the course of the Works; and
- that Works will be provided in accordance with any current relevant Australian/New Zealand Standards applicable.
- The Client shall obtain (at the expense of the Client) all licenses and approvals that may be required for the Works.
- The Contractor shall comply with the terms and conditions of all such consents and approvals in so far as such consents and approvals relate to the carrying out of the Works.
- Health and Safety Compliance
- The Client acknowledges that health and safety is a priority of the Contractor:
- acknowledging the Contractor’s health and safety priority, the Client will:
- ensure, as far as reasonably practicable, the health and safety of its workers and any other person influenced or directed by the Client;
- have in place a health and safety plan that is consistent with work health and safety laws (WHS) and the Contractor’s health and safety plan, and must provide a copy of that plan to the Contractor;
- comply with all directions and instructions from the Contractor regarding health and safety, and ensure that all staff, subcontractors, agents and any tenants of the Client comply all directions and instructions from the Contractor regarding health and safety, so far is reasonably practicable;
- consult, co-operate with and co-ordinate with all other users of the Worksite for the common purpose of ensuring the safety of all users of and visitors to the Worksite;
- immediately notify the Contractor of any hazards or risks to any person in relation to any work relating the Client’s activities, or any other activity arising from or affected by the Client’s activities;
- will ensure its staff and contractors exercise all care when traversing the Worksite; and
- as far as reasonably practicable, consult, co-operate with and co-ordinate activities with the Contractor in relation to health and safety matters;
- shall, as soon as possible after becoming aware that a notifiable event has occurred relating to the Worksite, notify the relevant authority and the Contractor of the event; and
- the parties agree that it is imperative that any breach of this clause 13 must be immediately remediated.
- acknowledging the Contractor’s health and safety priority, the Client will:
- The Client acknowledges that health and safety is a priority of the Contractor:
- Title
- The Contractor and the Client agree that ownership of the Materials shall not pass until:
- the Client has paid the Contractor all amounts owing to the Contractor; and
- the Client has met all of its other obligations to the Contractor.
- Receipt by the Contractor of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.
- It is further agreed that until ownership of the Materials passes to the Client in accordance with clause 1:
- the Client is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to the Contractor on request;
- the Client holds the benefit of the Client’s insurance of the Materials on trust for the Contractor and must pay to the Contractor the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed;
- the production of these terms and conditions by the Contractor shall be sufficient evidence of the Contractor’s rights to receive the insurance proceeds direct from the insurer without the need for any person dealing with the Contractor to make further enquiries;
- the Client must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Client sells, disposes or parts with possession of the Materials then the Client must hold the proceeds of any such act on trust for the Contractor and must pay or deliver the proceeds to the Contractor on demand;
- the Client should not convert or process the Materials or intermix them with other goods but if the Client does so then the Client holds the resulting product on trust for the benefit of the Contractor and must sell, dispose of or return the resulting product to the Contractor as it so directs;
- unless the Materials have become fixtures the Client irrevocably authorises the Contractor to enter any premises where the Contractor believes the Materials are kept and recover possession of the Materials;
- the Contractor may recover possession of any Materials in transit whether or not delivery has occurred;
- the Client shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of the Contractor;
- the Contractor may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not passed to the Client.
- The Contractor and the Client agree that ownership of the Materials shall not pass until:
- Personal Property Securities Act 2009 (“PPSA”)
- In this clause financing statement, financing change statement, security agreement, and security interest has the meaning given to it by the PPS
- Upon assenting to these terms and conditions in writing the Client acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of the PPSA and creates a security interest in all Materials and/or collateral (account) – being a monetary obligation of the Client to the Contractor for Works – that have previously been supplied and that will be supplied in the future by the Contractor to the Client.
- The Client undertakes to:
- promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Contractor may reasonably require to:
- register a financing statement or financing change statement in relation to a security interest on the Personal Property Securities Register;
- register any other document required to be registered by the PPSA; or
- correct a defect in a statement referred to in clause 3(a)(i) or 15.3(a)(ii);
- indemnify, and upon demand reimburse, the Contractor for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by the PPSA or releasing any Materials charged thereby;
- not register a financing change statement in respect of a security interest without the prior written consent of the Contractor;
- not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials and/or collateral (account) in favour of a third party without the prior written consent of the Contractor;
- immediately advise the Contractor of any material change in its business practices of selling the Materials which would result in a change in the nature of proceeds derived from such sales.
- promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Contractor may reasonably require to:
- The Contractor and the Client agree that sections 96, 115 and 125 of the PPSA do not apply to the security agreement created by these terms and conditions.
- The Client hereby waives its rights to receive notices under sections 95, 118, 121(4), 130, 132(3)(d) and 132(4) of the PPSA.
- The Client waives its rights as a grantor and/or a debtor under sections 142 and 143 of the PPSA.
- Unless otherwise agreed to in writing by the Contractor, the Client waives its right to receive a verification statement in accordance with section 157 of the PPSA.
- The Client shall unconditionally ratify any actions taken by the Contractor under clauses 3 to 15.5.
- Subject to any express provisions to the contrary (including those contained in this clause 15), nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions of the PPSA.
- Security and Charge
- In consideration of the Contractor agreeing to supply the Materials, the Client charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Client either now or in the future, to secure the performance by the Client of its obligations under these terms and conditions (including, but not limited to, the payment of any money).
- The Client indemnifies the Contractor from and against all the Contractor’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising the Contractor’s rights under this clause.
- The Client irrevocably appoints the Contractor and each director of the Contractor as the Client’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 16 including, but not limited to, signing any document on the Client’s behalf.
- Defects, Warranties and Returns, Competition and Consumer Act 2010 (“CCA”)
- The Client must inspect all Materials on delivery (or the Works on completion) and must within seven (7) days of delivery notify the Contractor in writing of any evident defect/damage, shortage in quantity, or failure to comply with the description or quote. The Client must notify any other alleged defect in the Materials/Works as soon as reasonably possible after any such defect becomes evident. Upon such notification the Client must allow the Contractor to inspect the Materials or to review the Works provided.
- Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (Non-Excluded Guarantees).
- The Contractor acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.
- Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, the Contractor makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Works. The Contractor’s liability in respect of these warranties is limited to the fullest extent permitted by law.
- If the Client is a consumer within the meaning of the CCA, the Contractor’s liability is limited to the extent permitted by section 64A of Schedule 2.
- If the Contractor is required to replace any Materials under this clause or the CCA, but is unable to do so, the Contractor may refund any money the Client has paid for the Materials.
- If the Contractor is required to rectify, re-supply, or pay the cost of re-supplying the Works under this clause or the CCA, but is unable to do so, then the Contractor may refund any money the Client has paid for the Works but only to the extent that such refund shall take into account the value of Works and Materials which have been provided to the Client which were not defective.
- If the Client is not a consumer within the meaning of the CCA, the Contractor’s liability for any defect or damage in the Materials is:
- limited to the value of any express warranty or warranty card provided to the Client by the Contractor at the Contractor’s sole discretion;
- limited to any warranty to which the Contractor is entitled, if the Contractor did not manufacture the Materials;
- otherwise negated absolutely.
- Subject to this clause 17, returns will only be accepted provided that:
- the Client has complied with the provisions of clause 1; and
- the Contractor has agreed that the Materials are defective; and
- the Materials are returned within a reasonable time at the Client’s cost (if that cost is not significant); and
- the Materials are returned in as close a condition to that in which they were delivered as is possible.
- Notwithstanding clauses 1 to 17.9 but subject to the CCA, the Contractor shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:
- the Client failing to properly maintain or store any Materials;
- the Client using the Materials for any purpose other than that for which they were designed;
- the Client continuing to use any Materials after any defect became apparent or should have become apparent to a reasonably prudent operator or user;
- interference with the Works by the Client or any third party without the Contractor’s prior approval;
- the Client failing to follow any instructions or guidelines provided by the Contractor;
- fair wear and tear, any accident, or act of God.
- Notwithstanding anything contained in this clause if the Contractor is required by a law to accept a return then the Contractor will only accept a return on the conditions imposed by that law.
- Intellectual Property
- Where the Contractor has designed, drawn, written plans or a schedule of Works, or created any products for the Client, then the copyright in all such designs, drawings, documents, plans, schedules and products shall remain vested in the Contractor, and shall only be used by the Client at the Contractor’s discretion. Under no circumstances may such designs, drawings and documents be used without the express written approval of the Contractor.
- The Client warrants that all designs, specifications or instructions given to the Contractor will not cause the Contractor to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify the Contractor against any action taken by a third party against the Contractor in respect of any such infringement.
- The Client agrees that the Contractor may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings, plans or products which the Contractor has created for the Client.
- Default and Consequences of Default
- An event of default (“Default Event”) occurs if:
- any money payable under this agreement is not paid before or on the due date for payment;
- the Client fails to observe and perform any of the Client’s covenants, other than the failure to pay money, and such failure continues for more than three (3) days after the Contractor had given the Client notice requiring the Client to remedy the breach;
- the Client, being an individual, commits an act of bankruptcy, is declared mentally ill or is convicted of a criminal offence or dies;
- a receiver, or an agent in possession for a mortgagee, is appointed in respect of any property of the Client;
- a mortgagee takes possession of any property of the Client;
- any execution or similar process is made against the property of the Client;
- an application is made, a resolution is passed or a meeting is convened for the purpose of considering a resolution for the Client to be wound up, unless the winding up is for the purpose of reconstruction or amalgamation;
- a compromise or arrangement is made between the Client and its creditors;
- a resolution is passed, or a meeting is convened for the purpose of considering a resolution for the Client to be placed under official management;
- the Client admits in writing its inability to pay its debts;
- On the occurrence of an Default Event:
- the Contractor may:
- take possession of the Materials with, or without notice to the Client, in accordance with clause 3(c);
- charge interest on overdue invoices, which shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and one half percent (2.5%) per calendar month (and at the Contractor’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment;
- if the Client owes the Contractor any money, the Client shall indemnify the Contractor from and against all costs and disbursements incurred by the Contractor in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, the Contractor’s contract default fee, and bank dishonour fees);
- further to any other rights or remedies the Contractor may have under this agreement, if the Client has made payment to the Contractor and the transaction is subsequently reversed, the Client shall be liable for the amount of the reversed transaction, in addition to any further costs incurred by the Contractor under this clause 3 where it can be proven that such reversal is found to be illegal, fraudulent or in contravention to the Client’s obligations under this agreement;
- without prejudice to the Contractor’s other remedies at law, the Contractor shall be entitled to cancel, suspend or terminate the supply of Works or any part of any order of the Client which remains unperformed in addition to and without prejudice to any other remedies the Contractor may have and all amounts owing to the Contractor shall, whether or not due for payment, become immediately payable. The Contractor will not be liable to the Client for any loss or damage the Client suffers because the Contractor has exercised its rights under this clause.
- the Contractor may:
- An event of default (“Default Event”) occurs if:
- Cancellation
- Without prejudice to any other remedies the Contractor may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions the Contractor may suspend or terminate the supply of Works to the Client. The Contractor will not be liable to the Client for any loss or damage the Client suffers because the Contractor has exercised its rights under this clause.
- The Contractor may cancel any contract to which these terms and conditions apply or cancel delivery of Works at any time before the Works are commenced by giving written notice to the Client. On giving such notice the Contractor shall repay to the Client any sums paid in respect of the Price, less any amounts owing by the Client to the Contractor for Works already performed. The Contractor shall not be liable for any loss or damage whatsoever arising from such cancellation.
- In the event that the Client cancels the delivery of Works the Client shall be liable for any and all loss incurred (whether direct or indirect) by the Contractor as a direct result of the cancellation (including, but not limited to, any loss of profits).
- Privacy Policy
- All emails, documents, images or other recorded information held or used by the Contractor is Personal Information, as defined and referred to in clause 3, and therefore considered Confidential Information. The Contractor acknowledges its obligation in relation to the handling, use, disclosure and processing of Personal Information pursuant to the Privacy Act 1988 (“the Act”) including the Part IIIC of the Act being Privacy Amendment (Notifiable Data Breaches) Act 2017 (NDB) and any statutory requirements, where relevant in a European Economic Area (“EEA”), under the EU Data Privacy Laws (including the General Data Protection Regulation “GDPR”) (collectively, “EU Data Privacy Laws”). The Contractor acknowledges that in the event it becomes aware of any data breaches and/or disclosure of the Client’s Personal Information, held by the Contractor that may result in serious harm to the Client, the Contractor will notify the Client in accordance with the Act and/or the GDPR. Any release of such Personal Information must be in accordance with the Act and the GDPR (where relevant) and must be approved by the Client by written consent, unless subject to an operation of law.
- Notwithstanding clause 1, privacy limitations will extend to the Contractor in respect of Cookies where the Client utilises the Contractor’s website to make enquiries. The Contractor agrees to display reference to such Cookies and/or similar tracking technologies, such as pixels and web beacons (if applicable), such technology allows the collection of Personal Information such as the Client’s:
- IP address, browser, email client type and other similar details;
- tracking website usage and traffic; and
- reports are available to the Contractor when the Contractor sends an email to the Client, so the Contractor may collect and review that information (“collectively Personal Information”)
If the Client consents to the Contractor’s use of Cookies on the Contractor’s website and later wishes to withdraw that consent, the Client may manage and control the Contractor’s privacy controls via the Client’s web browser, including removing Cookies by deleting them from the browser history when exiting the site.
- The Client agrees for the Contractor to obtain from a credit reporting body (CRB) a credit report containing personal credit information (e.g. name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) about the Client in relation to credit provided by the Contractor.
- The Client agrees that the Contractor may exchange information about the Client with those credit providers and with related body corporates for the following purposes:
- to assess an application by the Client; and/or
- to notify other credit providers of a default by the Client; and/or
- to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit providers; and/or
- to assess the creditworthiness of the Client including the Client’s repayment history in the preceding two (2) years.
- The Client consents to the Contractor being given a consumer credit report to collect overdue payment on commercial credit.
- The Client agrees that personal credit information provided may be used and retained by the Contractor for the following purposes (and for other agreed purposes or required by):
- the provision of Works; and/or
- analysing, verifying and/or checking the Client’s credit, payment and/or status in relation to the provision of Works; and/or
- processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Client; and/or
- enabling the collection of amounts outstanding in relation to the Works.
- The Contractor may give information about the Client to a CRB for the following purposes:
- to obtain a consumer credit report;
- allow the CRB to create or maintain a credit information file about the Client including credit history.
- The information given to the CRB may include:
- Personal Information as outlined in 3 above;
- name of the credit provider and that the Contractor is a current credit provider to the Client;
- whether the credit provider is a licensee;
- type of consumer credit;
- details concerning the Client’s application for credit or commercial credit (e.g. date of commencement/termination of the credit account and the amount requested);
- advice of consumer credit defaults, overdue accounts, loan repayments or outstanding monies which are overdue by more than sixty (60) days and for which written notice for request of payment has been made and debt recovery action commenced or alternatively that the Client no longer has any overdue accounts and the Contractor has been paid or otherwise discharged and all details surrounding that discharge(e.g. dates of payments);
- information that, in the opinion of the Contractor, the Client has committed a serious credit infringement;
- advice that the amount of the Client’s overdue payment is equal to or more than one hundred and fifty dollars ($150).
- The Client shall have the right to request (by e-mail) from the Contractor:
- a copy of the Personal Information about the Client retained by the Contractor and the right to request that the Contractor correct any incorrect Personal Information; and
- that the Contractor does not disclose any Personal Information about the Client for the purpose of direct marketing.
- The Contractor will destroy Personal Information upon the Client’s request (by e-mail) or if it is no longer required unless it is required in order to fulfil the obligations of this Contract or is required to be maintained and/or stored in accordance with the law.
- The Client can make a privacy complaint by contacting the Contractor via e-mail. The Contractor will respond to that complaint within seven (7) days of receipt and will take all reasonable steps to make a decision as to the complaint within thirty (30) days of receipt of the complaint. In the event that the Client is not satisfied with the resolution provided, the Client can make a complaint to the Information Commissioner at www.oaic.gov.au.
- Service of Notices
- Any written notice given under this Contract shall be deemed to have been given and received:
- by handing the notice to the other party, in person;
- by leaving it at the address of the other party as stated in this Contract;
- by sending it by registered post to the address of the other party as stated in this Contract;
- if sent by facsimile transmission to the fax number of the other party as stated in this Contract (if any), on receipt of confirmation of the transmission;
- if sent by email to the other party’s last known email address.
- Any notice that is posted shall be deemed to have been served, unless the contrary is shown, at the time when by the ordinary course of post, the notice would have been delivered.
- Any written notice given under this Contract shall be deemed to have been given and received:
- Trusts
- If the Client at any time upon or subsequent to entering in to the Contract is acting in the capacity of trustee of any trust (“Trust”) then whether or not the Contractor may have notice of the Trust, the Client covenants with the Contractor as follows:
- the Contract extends to all rights of indemnity which the Client now or subsequently may have against the Trust and the trust fund;
- the Client has full and complete power and authority under the Trust to enter into the Contract and the provisions of the Trust do not purport to exclude or take away the right of indemnity of the Client against the Trust or the trust fund. The Client will not release the right of indemnity or commit any breach of trust or be a party to any other action which might prejudice that right of indemnity;
- the Client will not without consent in writing of the Contractor (the Contractor will not unreasonably withhold consent), cause, permit, or suffer to happen any of the following events:
- the removal, replacement or retirement of the Client as trustee of the Trust;
- any alteration to or variation of the terms of the Trust;
- any advancement or distribution of capital of the Trust; or
- any resettlement of the trust property.
- If the Client at any time upon or subsequent to entering in to the Contract is acting in the capacity of trustee of any trust (“Trust”) then whether or not the Contractor may have notice of the Trust, the Client covenants with the Contractor as follows:
- Building Industry Fairness (Security of Payment) Act 2017
- At the Contractor’s sole discretion, if there are any disputes or claims for unpaid Materials and/or Works then the provisions of the Building Industry Fairness (Security of Payment) Act 2017 may apply.
- Nothing in this contract is intended to have the effect of contracting out of any applicable provisions of the Building Industry Fairness (Security of Payment) Act 2017 of Queensland, except to the extent permitted by the Act where applicable.
- General
- The failure by either party to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect that party’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.
- These terms and conditions and any contract to which they apply shall be governed by the laws of Queensland in which the Contractor has its principal place of business, and are subject to the jurisdiction of the courts in that state.
- Subject to clause 17, the Contractor shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by the Contractor of these terms and conditions (alternatively the Contractor’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Works).
- The Contractor may licence and/or assign all or any part of its rights and/or obligations under this Contract without the Client’s consent.
- The Client cannot licence or assign without the written approval of the Contractor.
- The Contractor may elect to subcontract out any part of the Works but shall not be relieved from any liability or obligation under this Contract by so doing. Furthermore, the Client agrees and understands that they have no authority to give any instruction to any of the Contractor’s sub-contractors without the authority of the Contractor.
- The Client agrees that the Contractor may amend their general terms and conditions for subsequent future contracts with the Client by disclosing such to the Client in writing. These changes shall be deemed to take effect from the date on which the Client accepts such changes, or otherwise at such time as the Client makes a further request for the Contractor to provide Works to the Client.
- Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.
- Both parties warrant that they have the power to enter into this Contract and have obtained all necessary authorisations to allow them to do so, they are not insolvent and that this Contract creates binding and valid legal obligations on them.